Construction Contracts in Context
14 pages
(3500 words)
, Download 2
In the absence of such a waiver, the court held that contractor was held not entitled to extension of time owing to failure on his part to serve notice.... ??variations and any other matters or instructions which under these Conditions are to be treated as, or as requiring, a variation”4 and “any impediment, prevention or default, whether by act or omission, by the Employer, the Architect/ Contract Administrator, the Quantity Surveyor or any of the Employer's Persons, except to the extent caused or contributed to by any default, whether by act or omission, of the Contractor or of any of the
...