StudentShare
Contact Us
Sign In / Sign Up for FREE
Search
Go to advanced search...
Free

Implementation of Contract JCT - Essay Example

Cite this document
Summary
The paper "Implementation of Contract JCT" tells that Contract administration is the process and procedures entailed towards ensuring the successful delivery of civil engineering projects. Acting on behalf of the employer, the administrator coordinates all the activities contained within the contract…
Download full paper File format: .doc, available for editing
GRAB THE BEST PAPER94.5% of users find it useful
Implementation of Contract JCT
Read Text Preview

Extract of sample "Implementation of Contract JCT"

? Contractual Procedures: Report on the Recommendation for Implementation of Contract JCT SBC . dueIntroduction Contract administration is the process and procedures entailed towards ensuring the successful delivery/ implementation of a civil engineering project. Acting on behalf of the employer, the administrator coordinates all the activities contained within the contract to ensure their successful and practical implementation (Ashworth 2006). Consequently, there are various activities that must be coordinated with the key concerns being cost and time. The project must be delivered within the stipulated time and within the projected budget cost. Such expectations with time require strict operation and ultimate discipline especially with procurement and implementation. Considerations when Accepting a Contractor’s Work Programme When evaluating the possibility of accepting a contractor’s work programme in regard to a construction project, various points must be considered. Ashworth (2006) asserts that the key concerns towards the acceptance of the programme will be considered in the pre-construction conference. During this conference, I as the contract administrator will verify whether the contractor has been able to provide pre-requisite documents as required for the project before issuing the Notice to Proceed. These documents include certificates of insurance, letters of credit as bond for the project cost which should be 40% of the project cost, building permits and contractor’s license. This process ensure that third party liability and accidents surrounding the project are adequately covered thus ensuring the safety of the project. The contractor’s license will give an assurance towards the eligibility of the contractor and give an indication into his experience to carry out the stipulated works (Chappell 2006). Further to the contractor complying with the documentation and security and safety measures, it is important to ensure that the contractor will be able to accomplish the project requirements within the time lines. In this regard, the proposed programme provided by the contractor is to be evaluated to ascertain practicability. The programme should ensure that the construction works are completed in good time to allow for inspection and mitigation where issues could arise (Stoll & Reilly 2006). The programme provided by the contractor in this project does not include road improvement and cabling works. However, this programme runs into the expected time for completion of the entire project. Though the cabling works is a separate contract by another contractor, it is clear that the road improvement and electricity cabling works should come after the construction of the production units and so the contractor should have allowed enough time for such related works. In light of the above, as the Contract Administrator, I will not be able to approve such a programme due to the risk of not being able to deliver the project within the time deadline. Advice to Help Complete the Construction work earlier From the initial contract agreement, the lead contractor is to take charge of the construction of the factory units and the improvement of the service lane as well as the junction with the dual carriageway. The other works of diversion of electrical cabling is to be undertaken by a different contractor but one who must start work after the construction of the factory unit and the service lane. Therefore, to ensure that all the project deliverables are achieved within the deadline of 1st June, the construction of the factory units and the service lane must be completed before then. Consequently for the construction work to be completed by mid May, the employer has three options to pursue: a. The employer may have to bring forward the commencement date so that the actual construction work begin two weeks earlier. This could mean the works beginning by mid December as opposed to 1st January. This is likely to be impossible because of the festivities making it logistically difficult. b. Secondly, the employer might urge the contract on the construction project to increase his capacity and manpower so has to pursue the construction work and improvement of the service lane concurrently. With increased man power and equipment, the contractor will be able commission the work of construction and improvement of the service lane and the junction at the same time without compromising the quality of the work. The main Contractor could also sub-contractor some of the work to a qualified contractor upon agreement with the employer. In this case the other works would be running simultaneously without compromising the quality of work thus meeting the tight schedule. c. Finally, the employer can renegotiate the contract with the view of removing some aspects of the scope which are independent such as separating the works of construction of the factory units with improvement of service lane. One aspect of the work can then be offered to a separate contractor. By doing so, the employer is in charge of all the contractors though this might involve protracted negotiations and run away with time. Therefore, as the contract administrator, I would advise the employer to urge the contractor to sub contractor part of the work to qualified sub contractor who will also be bound by the original contract. Effect of adverse Weather on Contract Administration In order to address the issue of adverse weather in the implementation of a civil engineering and construction project, the contract should provide clauses to deal with time extensions due to adverse weather conditions. With this regard, I will expect the contractor top record daily and monthly weather variations and its impact on the implementation of the project. Prior to the recording, it is expected that the programme presented by the contractor upon the issuance of notice to proceed should be able to take care of any anticipated bad weather. However, some cases of bad/adverse weather are unforeseen. It is the unforeseen adverse weather conditions which can necessitate time extensions (Holland & Lamont 2007). During the course of project implementation, the actual days affected by adverse weather are noted simultaneously with the parameters and components of the construction work that could or was affected by the weather. The administrator will have to ascertain whether the activities were actually affected by the weather conditions. These adverse weather days are considered as full days even if their impact could not last the whole day. The contract administrator must also consider that some aspects of adverse weather now could affect future works such as setting formwork as well as concreting. Upon determining the effective work days affected by the adverse weather during the two week period, the administrator will have to understand whether the works were affected and consequently provide time extension to cover the affected work period. The time extension will be equivalent to actual days affected, especially if the weather was not foreseen. Application of Liquidated Damages Clause where it is not included in the Contract In application of the liquidated damages clause, various factors will have to be considered. Inevitably, the contract administrator must consider whether such a clause exists in the contract. Further, the actually delay period must be considered with the effect of adverse weather being incorporated to allow for time extension. In the case of contract JCT SBC (2011), there is no clause for liquidated damages and so it cannot be implemented. However, the employer should consider seeking for actual damages if they can be quantified. The duration of delay upon determination from the effect of adverse weather conditions is two weeks and not four weeks as evident in the delay by the contractor based on the completion date. According to Williams (2010), the greatest challenge is to determine the actual damages incurred due to the two week delay. Therefore, the owner should sue for damages in terms of the actual loss from the factory operations if it was to be in operation during the period of delay. This would be difficult to implement but can be implemented once the actual damages are determined. However operations such as delays and inconveniences caused on the junction could be very difficult to determine and hence could be dismissed by the courts as unenforceable. Application of Liquidated damages in case of a Provision Having previously determined that the contract was substantially completed four weeks into the deadline time, liquidated damages are applicable based on the time run out which can be determined as actual delay and which is not covered by the extension caused by other factors such as adverse bad weather. In the case of this contractor, it has adequately been justified that the extension on time deadline could be granted based on the two weeks delay caused by bad weather. This leaves an extra two weeks in the completion time (Williams 2010). Based on this understanding, the owner should be able to sue for liquidated damages up to two weeks at the presupposed pre agreed rate of $2,000 per week. On behalf of the owner, I would sue for $4,000 in liquidated damages. References Ashworth, A 2006, Contractual procedures in the construction industry (5th ed.). Harlow, England: Pearson/Prentice Hall. Chappell, D 2006, IC05: contract administration : completing the contract and administration forms. London: RIBA Publishing. Holland, G & Lamont, C 2007, Contract administration. Coventry: RICS Books. Stoll, B & Reilly, J 2006, Methodologies for determining construction contract time and evaluating contract time extensions. Clemson, SC: Dept. of Civil Engineering, Clemson University ;. Williams, T 2010, Construction management: emerging trends and technologies. Clifton Park, N.Y.: Delmar/Cengage Learning. Read More
Cite this document
  • APA
  • MLA
  • CHICAGO
(“Coursework 2 Essay Example | Topics and Well Written Essays - 1250 words”, n.d.)
Coursework 2 Essay Example | Topics and Well Written Essays - 1250 words. Retrieved from https://studentshare.org/engineering-and-construction/1474402-coursework
(Coursework 2 Essay Example | Topics and Well Written Essays - 1250 Words)
Coursework 2 Essay Example | Topics and Well Written Essays - 1250 Words. https://studentshare.org/engineering-and-construction/1474402-coursework.
“Coursework 2 Essay Example | Topics and Well Written Essays - 1250 Words”, n.d. https://studentshare.org/engineering-and-construction/1474402-coursework.
  • Cited: 0 times

CHECK THESE SAMPLES OF Implementation of Contract JCT

Not Enough Thought Has Been Given in any European Code to the Way Contracts Should Be Classified

The first step has been termed the PECL and is aimed at unifying the contract law prevalent throughout Europe.... The PECL is a broad attempt to create a set of 'general rules' which are flexible enough to accommodate future developments and to provide a framework for contract law.... Here due consideration must be provided to the fact that contract law is the first thing that is being attempted in terms of a common legal framework for a number of reasons....
13 Pages (3250 words) Essay

Legal Systems and Contract Law in the UK

There is a general issue with acceptance of contract offers by post.... Scottish Civil Law The relevant aspect of the Scottish civil law that is relevant in the law of contract relate mainly to promises, counter offers and remedies.... Part 1 This section advises Calum on whether his acceptance of the offer of Tom through his post constitutes a valid contract or not.... Whether the second mail sent on the 29th with an unconditional acceptance created a valid contract or not even though it was received on the 2nd of September – two days after the deadline....
12 Pages (3000 words) Essay

Hospitality Contract and Event Management

HOSPITALITY AND EVENT MANAGEMENT by Code+ University name Date Main characteristics of the contract and event catering sectors A contract in the catering sectors involves an agreement between a person who provides catering services and a person with an event that requires catering services such as food supply among other services.... The reason why people enter a contract with caterer is because caterers provide quality services since they are professional in those sectors....
10 Pages (2500 words) Assignment

Contractual Procedures

ECC form of contract has its origins in New Engineering Contracts (NEC).... ECC contract philosophy is fundamentally different from JCT wherein programme management and change management during the implementation of the contract are well defined and... Thus unlike jct measurement of work and application of rates are the core of payments actually made.... jct contracts are still burdened under heavy legal framework is used more as a deterrent to dissenting parties rather than to bring them close to negotiation....
3 Pages (750 words) Book Report/Review

The Role of the Contract Administrator under a JCT Traditional Contract

owl and Skitmore (2005) have surveyed project managers of construction projects who also have the duties of contract administrator and have claimed that in certain cases project managers are overworked although there may be several hindrances to their effectiveness in the management.... Issues that could help in making project managers more effective and productive in their job include more awareness and participation within their own organisation for progress and development of the organisation, more general administrative support and greater responsibilities in matters of contract administration3....
9 Pages (2250 words) Essay

Recognizing Contract Risk and Opportunities

All the companies are responsible to fulfilling the contracts as failure to comply contributes to the breach of contract in terms of poor performance and organizational alterations.... need for organizations adhering to contract stipulations and terms plus the implementation of know-how to assist in the scrutinizing and administering of compliance.... For example, approximately 80 percent of organization experience obscurities in establishing contracts such as In contract management process compliance is the most difficult part because the capacity to implement conformity internally (employees) and externally (suppliers) is rigid in the overall management process....
8 Pages (2000 words) Essay

Analysis of Construction Contract Law of the United Kingdom

The promulgation of the Local Democracy, Economic Development and Construction Act 2009 (LDEDCA) on 1st October 2011 reformed the regulation of construction agreements that have come into effect since then and is the foundation of this contract.... The main aim of the reforms was to correct perceived misgivings in the 1996 Act and keep construction industry in line with the current trends and quality and stringent This paper examines various clauses of the Sub-contract and their level of compatibility with the Construction Act 2009 and the Joint Contracts Tribunal rules....
12 Pages (3000 words) Essay

JCT Design & Build Contract

jct 2011 Design and Build Contract provides various provisions on how contactors should deal with alterations to the original terms of the contracts when valuing additional works.... Another change regarding the payments is that if one party fails to issue notice of payment as the contract requires, the other party can step in and issue such notice, extending the date for final payment.... For instance, contractors can recover some of their funds for the work done when a contract is suspended....
4 Pages (1000 words) Coursework
sponsored ads
We use cookies to create the best experience for you. Keep on browsing if you are OK with that, or find out how to manage cookies.
Contact Us