StudentShare
Contact Us
Sign In / Sign Up for FREE
Search
Go to advanced search...
Free

Risk Allocation in FIDIC - Assignment Example

Cite this document
Summary
The paper "Risk Allocation in FIDIC" highlights that the efficient FIDIC administration contracts of construction are necessary to make certain that claims of time and money are saved. It is significant to put notices in writing in definitive and clear terms don’t suggest or hint…
Download full paper File format: .doc, available for editing
GRAB THE BEST PAPER92.2% of users find it useful
Risk Allocation in FIDIC
Read Text Preview

Extract of sample "Risk Allocation in FIDIC"

? Risk Allocation in FIDIC of [Word Count = 2304] Risk Allocation in FIDIC Introduction The InternationalFederation of Consulting Engineers which is better recognized because of its French term “Federation Internationale des Ingenieurs Conseils (FIDIC)” was first published in 1957.1 The aim of FIDIC was to encourage the engineering consulting interests of institutions throughout the world. Now the FIDIC is used over a great extent as a standard for the contacts that are of international standard. The forms of FIDIC reflect the usual standard for different types of international contracts all over the world.2 Nowadays it is well-known because of its variety of contract’s standard terms for the plant, construction, as well as for the designing industries. Headquarter of FIDIC is situated in Switzerland, more than sixty countries are the part of FIDIC and it also represents many of the private consulting engineers all over the world. A variety of standard forms are made and published by FIDIC and are regularly updated following of extensive consultation with its international contractors, members, the Bar Institution and with the main international banks as well as the World Bank.3 Discussion At the beginning the standard forms of the FIDIC were aimed for international usage i.e. for those projects in which the client country was looking for contractor’s participation from other countries. Even so in current period the forms of the FIDIC have been used more and more for local contracts in which both contractors and clients are of the same country.4 In 1999, after the development in the industry and following the acknowledgment of irregularity in the previous contract’s standard, the FIDIC developed a new form’s suit in order to change the active forms. The FIDIC Family of Contracts In 1999, new contract’s Rainbow Suite of FIDIC was released and these include: The Red Book: these are the contract’s terms for the function of Engineering which is planned by the company as well as for the creation of Building; The Yellow Book: this includes the contract’s terms in order to plan and establish structure;5 The Silver Book: These are the contract’s terms for Turnkey / Engineering, Procurement and Construction Tasks; 6 The Green Book: these are the concise contract’s form. The design of these new is to be user friendly with the standard approach and a decrease in the general conditions from over sixty to twenty clauses. In addition to this the Extra forms functioning since 1999 consist of: The Blue Book: these are the contracts for Dragging and Renewal of Works; The Multilateral Development Banks (MDBs) /FIDIC Contract: these are the condition of FIDIC that are integrated in the standard papers of request of MDBs;7 The White Book: this include the form contract of service of Consultant and Client; The Gold Book: this includes the operation, building and designing of the FIDIC tasks.8 To aid in carrying out its establishing aims, the move towards of the FIDIC in order to outline contracts has constantly been supported by its principle. The contracts of FIDIC necessarily furnish a reasonable part of risks among the parties to a contract, additionally that risks must be accepted by the best able party in order to assure them. The uniformity across many forms is one of the advantages of utilizing the FIDIC set of contracts. Whilst all contract form is aimed for a dissimilar type of procurement or project strategy, a centre of general clauses is utilized over the entire forms and where probable, the identical definitions and words are utilised. 9This implies that know-how of one type can be utilised on other types in the FIDIC set of contracts. Within the suite of FIDIC the different types of contracts are prepared across the degree of plan responsibility presumed by the contractor and employer. Every contract is termed as a book and a specific colour is assigned to each contract. Understanding the Contract and General Provisions The structure of the Yellow and Red is similar, with twenty common conditions. These books have direction in order to help in the preparation of specific circumstances as well as the choice to add Specific Terms. The Red Book: (these are the contract’s terms for the function of engineering which is planned by the company and for the creation of the building) is aimed to be utilised when the employer is accountable for the designing of the forms. This book is a contract of re-measurement, intending that the contractor and the employer will have the same opinion on their contract the kind of work rates and these rates must be employed to the extent of that work that is carried out by the contractor. The risks that employer accepts that its estimated quantities will be accurate to some extent, whilst the contractor shall ensure adequate prices of its unit quantities.10 The Yellow Book: (this includes the contract’s terms in order to plan and establish formation) is aimed for the utilisation when the contractor proposes the functions. This book is a contract with a complete payment consisting of a single sum of money, in this contract the contractor assures to carry the project for a fixed price. Therefore the quantities risk is taken by the contractor.11 Silver Book: The contract type of the FIDIC is outlined on the fundamental principle in which the risk must be owed to that party which is most effective to control and bear that risk. It implies that the contractor is not guilty for circumstances and no needed to price that are unknown to him or those which couldn’t be fairly predictable at the time of his bid. This results in the creation of uncertainty as to time and price when such circumstances come up on a project. Earlier to the progress of Silver Book, in order to avoid such risks most of the employers make changes in the balance of risks in the Yellow or Red Book by putting a greater liability over the contractor. Green Book: For the construction of small projects and home, a general event is the function of the Red Book. Most of the time, it is incompatible and might cause more confrontations than it resolves. In such conditions the green book is recommended when the parties like to remain within the family of FIDIC on small-scale tasks. This type of contract is aimed for construction and engineering function of smaller projects in which the work is repetitious or easy with no need for specialist contractors. 12 All books of FIDIC determine the engineer’s role basically as the employer’s agent. The primary responsibility of an engineer is the contract administration. The engineer function includes: Acts as certifier. Issues notices and instructions; Supervises the works; In Yellow and Red books the engineers are no more declared to be unprejudiced, the engineer is viewed as to and in practical applications does act as for the employer.13 The primary responsibility of the contractor under any contract of construction is as might be expected the completion and construction of the works within the fixed time period for completion and according to the contract. Under the yellow and red books its other duties include:14 Accomplishing the functions in a competent and proper way with accurately furnished facilities and non-risky resources; Design obligation; Fitness for a reason – assuring that its purpose will satisfy the requirements of the employer; Furnishing those services and preferring those resources; Obligation for working method. It also the responsibility of the contractor to execute certain functions that are administrative as well as the other functions in order to ease operation, together with rendering information required for the completion and execution of the works, and also the notices issuance with the events that increases cost or time of completion.15 How to Avoid Pitfalls Claims of the Contractor. Under the Red and Yellow Books the primary obligation is the necessity to notify in a claim’s respect for additional payments or time extension. The contractor is required to notify his aim to claim as shortly as possible and shouldn’t be delayed beyond 28 days once the contractor has been made aware, or ought to get aware, of an issue. The contractor then is required to submit a completely detailed claim in a period of 42 days of getting the awareness of an event or conditions that brought about to a claim.16 Formerly, failure in compliance with the prescribed time constraints entailed that any compensation to be confined to sums backed by modern-day records. Now, no such claim to compensation is required in case of the failure in compliance by the contractor. Adjustments and Variations. Utilizing the Red and Yellow Books, a variance for alterations to the works can come up by: The instruction of an employer;17 Proposal requested by an employer; ‘Value engineering' proposal requested by the contractor. The contract itself or the guarantees in situ for the project may be adversely affected by the variations, for instance by declining the safety or suitableness of the works. So an immediate monitoring or flagging up is required. A contractor could be liable even if the only requirement is to follow an engineer’s instructions. Compliance with the variations requested by an employer is obligatory on a contractor unless it is unable to easily access the required goods and material for the desired variation. However an issue regarding the determination of variation in terms of engineer’s suggestion may arise. This is deemed on the basis of facts of a specific event. It has been provided by The Red and Yellow Books that if instructions are given by an engineer orally, and these instructions are confirmed by the contractor in writing during a period of two working days then, if this confirmation is not rejected by engineer during two working days, such deed will confirm the engineer’s consent and thus will lead to the constitution of an engineer’s written instructions. It is hence very essential to assure that any spoken instruction that alters the ambit of the works requires a written confirmation unless instructed or approved by an engineer, the contractor cannot alter or modify the works. Time Extension And Delay. The liability of damages will be on contractor if the work is actually completed on a date after the agreed date of completion except the cause of the delay is due to an affair for which a time extension is provided and the compliance to the notice and other requisites has been ensured by the contractor under the contract. The entitlement of time extension may be specified to contractor in case there is. An additional work or variation is instructed; unpredictable shortages in the accessibility of goods or personnels; exceptionally unpleasant weather;18 delay induced by the employer; delay caused due to any other clause within the contract; Unpredictable delay made by abiding by the public office procedures. The contractor is required to strictly abide by the notification requirements prescribed by the contract, along with giving all essential information demanded against a claim. Significance of Keeping Records Maintaining enough records is necessary because: act in accordance with the responsibilities of reporting of the contract; protect claims of the subcontractor; Show titles to time and money. Decision of the ways of recording and the types of records at the beginning should be kept, assuring as it might be expected that this also fulfil the contract.19 Conclusion The efficient FIDIC administration contracts of construction are necessary to make certain that claims of time and money are saved. It is significant to put notices in writing in definitive and clear terms don’t suggest or hint. Maintenance of effective records will help employers and contractors to verify their claims and facilitate both parties to perfectly determine their places in the consequence that an argument arises. Additionally, it is friendly for the both the employers and the contractors, taking whole of the necessary clauses that FIDIC is well-known for but removing the feature of administration which might be not needed on a projects that are small scale. References Anonymous, Standard Form Contracts: FIDIC' (Oulaw.com 2011) accessed 20 October 2012 Chern, C., Chern on Dispute Boards (John Wiley & Sons, 2011) 45-55 Galloway, P.D., Nielsen, K.R. & Dignum, J.L., Managing Giga projects: Advice from Those Who've Been There, Done That (ASCE Publications, 2012) 115-125 Glover, J., Understanding the New Fidic Red Book (Sweet & Maxwell, 2012) 77-87 Huse, J.A., Understanding and Negotiating Turnkey and EPC Contracts (Sweet & Maxwell, 2002) 139-149 Icheme, Form of Contract, Subcontracts, the International Yellow Book (IChemE, 2007) 76-78 Jaeger, A. & Hok, G., FIDIC - A Guide for Practitioners (Springer, 2009) 34-45 Jenkins, J. & Stebbings, S., International Construction Arbitration Law (Kluwer Law International, 2006) 23-33 Knutson, R., & Abraham, W., Fidic: An Analysis of International Construction Contracts International Bar Association Series (Kluwer Law International, 2005) 124-135 Potts, K., Construction Cost Management: Learning from Case Studies (Routledge, 2008) 50-60 Robinson, M.D., A Contractor's Guide to the FIDIC Conditions of Contract (John Wiley & Sons, 2011) 94-104 Thomas, C., Glover, J & Hughes, S., Understanding the New FIDIC Red Book: A Clause-by-clause Commentary (Sweet & Maxwell, 2006) 78-88 Totterdill, B.W., FIDIC Users' Guide: A Practical Guide to the 1999 Red and Yellow Books (Thomas Telford, 2006) 103-113 Wright, D., International Form of Contract User Guide, The International Purple Book. (IChemE, 2007) 51-61 Wright, D., Purple Book - Forms of Contract User Guide. (IChemE, 2004) 201-211 Read More
Cite this document
  • APA
  • MLA
  • CHICAGO
(“Risk Allocation In FIDIC Assignment Example | Topics and Well Written Essays - 2000 words”, n.d.)
Risk Allocation In FIDIC Assignment Example | Topics and Well Written Essays - 2000 words. Retrieved from https://studentshare.org/law/1459119-risk-allocation-in-fidic
(Risk Allocation In FIDIC Assignment Example | Topics and Well Written Essays - 2000 Words)
Risk Allocation In FIDIC Assignment Example | Topics and Well Written Essays - 2000 Words. https://studentshare.org/law/1459119-risk-allocation-in-fidic.
“Risk Allocation In FIDIC Assignment Example | Topics and Well Written Essays - 2000 Words”, n.d. https://studentshare.org/law/1459119-risk-allocation-in-fidic.
  • Cited: 0 times

CHECK THESE SAMPLES OF Risk Allocation in FIDIC

Financial Modeling Of Value At Risk Portfolio

The analysis is carried out on the value at risk of a portfolio of four shares employing the techniques deployed in financial modeling.... The report is carried out on a 260-day value-at-risk (VAR) of the portfolio of the shares used to make the report.... This following report aims to analyze, justify, explain, recommend and conclude on the financial modeling outcomes of four shares of four different companies....
20 Pages (5000 words) Essay

Disputes through Arbitration in FIDIC Construction Contracts

Resolution of Disputes by Subcontractors through Arbitration in fidic Construction Contracts S.... 1 “Force Majeure Clause in fidic” 24 2.... The main advantages of using fidic 2011 Subcontract form 12 2.... fidic 2011 SUBCONTRACT CONDITIONS 12 2.... Dispute Resolution Mechanism for Subcontracts under the 2011 fidic Subcontract Procedures 14 2.... What is New in the fidic Subcon.... Under the non-excusable delay, the contractor bears the risk of outcome and cost, not only for himself but also for the resulting effect on the others like subcontractors also....
38 Pages (9500 words) Dissertation

The FIDIC 1999 Red Book

Overall, risk allocation notions and philosophies recognize standards of fair risk-allocation, like the following: 1.... This paper 'The fidic 1999 Red Book' seeks to explore the distribution of risks as per the fidic code between various parties namely the employer, the contractor and the engineer in order to discover how risks are fairly allocated.... The author states that in 2007, the UAE government adopted new contracts, based on the broad principles of the fidic conditions for construction, plant and design and build form of contracts....
8 Pages (2000 words) Essay

Contract In Fidic Red Book

This assignment "Contract in fidic Red Book" focuses on all construction contracts that do contain some magnitude of risk and there is a need to define the allocation of opportunities and risks.... fidic contract facilitates the allocation of risk between the contractor and the employer.... Red Book of fidic states that it has been drafted with sharing of risks between the parties in a construction contract evenly.... fidic Red Book allocates and classifies the various perils in a construction contract....
7 Pages (1750 words) Assignment

Conditions of Work for Civil Engineering Construction

It is also highly adaptable, provides a range of options for risk allocation.... In this paper 'Conditions of Work for Civil Engineering Construction,' the core clauses of NEC and fidic are compared with particular emphasis to the core risks.... Procedures under the fidic, are based on written notices where the contractor is required to write warning notices on unexpected costs and delays and their implications on the project.... In dealing with an unexpected situation, NEC has a range of provisions offering compensation for the events or occurrences that are at the employer's risk....
7 Pages (1750 words) Assignment

The English Contract Law

The roots of this body are in lex mercatoria and the judiciary activism during the industrial revolution, which has led to it sharing its heritage with other countries across the.... ... ... The English contract law is also experiencing gradual changes due to the membership of UK of international organizations and the European Union....
15 Pages (3750 words) Essay

Conceiving and Drafting of Terms of EPC Contracts

From the paper "Conceiving and Drafting of Terms of EPC Contracts" it is clear that fidic has released a new form of contract that can be used with design and construction of projects employing the engineering, procurement and construction contractor turnkey contracting basis.... The drafters of the EPC contract has to pay special attention to the allocation of project risks and with specific reference to the drafting of common terms in EPC contracts.... This research essay analyses the points to be taken into consideration while drafting the terms of international EPC contract and allocation of risks in the EPC contract so that the interests of both the contracting partiesAn EPC Contract is also known as fast-track contract....
21 Pages (5250 words) Research Paper

An Analysis of Two Engineering Forms of Contract

"An Analysis of Two Engineering Forms of Contract" paper states that according to many contractors' opinions NEC has most likely benefits as compared to fidic significantly in characteristics such as clarity, flexibility, precisely communicated project management processes, cooperation and teamwork.... fidic is drafted as a turnkey contract.... NEC has more advantages in risk management, targeted measurements of weather and ground considerations risks, and modifications....
12 Pages (3000 words) Coursework
sponsored ads
We use cookies to create the best experience for you. Keep on browsing if you are OK with that, or find out how to manage cookies.
Contact Us